Terms & Conditions
Last updated: 5 November 2026
These Terms and Conditions apply to your use of highlinks.ae (the “website”), which is operated by High Links Real Estate LLC (“High Links”, “we”, “us”), Building 10, Bay Square, Business Bay, Dubai, United Arab Emirates. By using the website you agree to them. If you do not agree, please do not use the website.
1. Information only
The website is a guide to off-plan projects, developers and communities in Dubai and the UAE. Everything on it is general information. It is not an offer, a contract, financial or investment advice, or legal advice.
2. Prices, availability and details can change
Prices, payment plans, floor areas, handover dates, availability, images, renders and descriptions come from developers and other sources and are indicative only. They can change without notice and may not be current. Images and renders are illustrative and may differ from the finished property. Always confirm the details of any property with us and with the developer before making a decision, and read the sale and purchase agreement carefully before you sign.
3. Off-plan properties and investment
Buying property, especially off-plan, involves risk, including delays, changes to plans, and changes in market value or rental returns. Past performance, forecasts and yields mentioned on the website, including in our articles, are not guarantees. You should obtain independent legal and financial advice before buying.
4. Our role
High Links acts as a real estate brokerage that introduces buyers and tenants to properties and developers. A transaction is made only between you and the developer or owner under a written agreement. Nothing on the website creates a broker–client agreement or any commitment from us until we confirm it in writing.
5. Enquiries
When you send an enquiry you agree that we may contact you about it by phone, WhatsApp or email. Please give accurate details. How we handle your data is explained in our Privacy Policy.
6. Using the website
You agree not to misuse the website. This includes trying to gain unauthorised access, interfering with how it works, sending spam through our forms, collecting its content by automated means in bulk, or using it for any unlawful purpose.
7. Intellectual property
The website’s design, text, logos and other content belong to High Links or its licensors, or to the developers whose project materials are shown. You may view and share pages for your own personal, non-commercial use. You may not copy, republish or sell the content without our written permission.
8. Third-party websites and services
The website may link to other websites and services, such as WhatsApp or developer websites. We do not control them and are not responsible for them.
9. No warranties and limits on liability
We try to keep the website accurate and available, but we provide it “as is” and do not promise that it is free of errors, complete, up to date or always available. To the fullest extent the law allows, High Links is not liable for any loss arising from your use of or reliance on the website. Nothing in these terms limits liability that cannot be limited by law.
10. Changes
We may change the website, and these terms, at any time. The date at the top shows when the terms were last updated. Continuing to use the website after a change means you accept it.
11. Governing law
These terms are governed by the laws of the Emirate of Dubai and the federal laws of the United Arab Emirates that apply there. The courts of Dubai have jurisdiction over any dispute about them.
12. Contact
High Links Real Estate LLC
Building 10, Bay Square, Business Bay, Dubai, UAE
[email protected] · +971 58 519 8540